Purchase Contract
合同
劳动合同范本免费下载装修合同范本免费下载租赁合同免费下载房屋买卖合同下载劳务合同范本下载
编号(Contract No.): _______________
签订日期(Date) :＿＿＿＿＿＿＿＿＿＿_
签订地点(Signed at) :＿＿＿＿＿＿＿____
买方：＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿
The Buyer:＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿
地址： ＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿
Address: ＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿
电话(Tel):___＿＿＿＿＿＿＿＿ 传真(Fax):＿＿＿＿＿＿＿＿＿＿
电子邮箱(E-mail):＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿
卖方：＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿
The Seller:＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿
地址：＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿
Address: ＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿_＿
电话(Tel):_＿＿＿＿＿＿＿＿ 传真(Fax):＿＿＿＿＿＿＿＿＿＿＿
电子邮箱(E-mail):＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿
买卖双方同意按照下列条款签订本合同：
The Seller and the Buyer agree to conclude this Contract subject to the terms and conditions stated below:
1. 货物名称、规格和质量（Name, Specifications and Quality of Commodity）：
2. 数量（Quantity）：
允许＿＿＿＿的溢短装（＿＿＿% more or less allowed）
3. 单价（Unit Price）：
4. 总值（Total Amount）：
5. 交货条件(Terms of Delivery) FOB/CFR/CIF＿＿＿＿＿＿＿
6. 原产地国与制造商 (Country of Origin and Manufacturers):
7. 包装及标准（Packing）：
货物应具有防潮、防锈蚀、防震并适合于远洋运输的包装，由于货物包装不良而造成的货物残损、灭失应由卖方负责。卖方应在每个包装箱上用不褪色的颜色标明尺码、包装箱号码、毛重、净重及“此端向上”、“防潮”、“小心轻放”等标记。
The packing of the goods shall be preventive from dampness, rust, moisture, erosion and shock, and shall be suitable for ocean transportation/ multiple transportation. The Seller shall be liable for any damage and loss of the goods attributable to the inadequate or improper packing. The measurement, gross weight, net weight and the cautions such as "Do not stack up side down", "Keep away from moisture", "Handle with care" shall be stenciled on the surface of each package with fadeless pigment.
8. 唛头（Shipping Marks）：
9. 装运期限（Time of Shipment）：
10. 装运口岸（Port of Loading）：
11. 目的口岸（Port of Destination）：
12. 保险（Insurance）：
由＿＿＿＿按发票金额110%投保＿＿＿＿＿险和＿＿＿＿＿附加险。
Insurance shall be covered by the ________ for 110% of the invoice value against _______ Risks and __________ Additional Risks.
13. 付款条件（Terms of Payment）：
(1) 信用证方式：买方应在装运期前/合同生效后＿＿日，开出以卖方为受益人的不可撤销的议付信用证，信用证在装船完毕后＿＿日内到期。
Letter of Credit: The Buyer shall, ______ days prior to the time of shipment /after this Contract comes into effect, open an irrevocable Letter of Credit in favor of the Seller. The Letter of Credit shall expire ____ days after the completion of loading of the shipment as stipulated.
(2) 付款交单：货物发运后，卖方出具以买方为付款人的付款跟单汇票，按即期付款交单（D/P）方式，通过卖方银行及＿＿＿＿＿银行向买方转交单证，换取货物。
Documents against payment: After shipment, the Seller shall draw a sight bill of exchange on the Buyer and deliver the documents through Sellers bank and ______ Bank to the Buyer against payment, i.e D/P. The Buyer shall effect the payment immediately upon the first presentation of the bill(s) of exchange.
(3) 承兑交单：货物发运后，卖方出具以买方为付款人的付款跟单汇票，付款期限为＿＿＿＿后＿＿日，按即期承兑交单(D/A＿＿日)方式，通过卖方银行及＿＿＿＿＿＿银行，经买方承兑后，向买方转交单证，买方在汇票期限到期时支付货款。
Documents against Acceptance: After shipment, the Seller shall draw a sight bill of exchange, payable_____ days after the Buyers delivers the document through Seller’s bank and _________Bank to the Buyer against acceptance (D/A ___ days). The Buyer shall make the payment on date of the bill of exchange.
(4) 货到付款：买方在收到货物后＿＿天内将全部货款支付卖方（不适用于FOB、CRF、CIF术语）。
Cash on delivery (COD): The Buyer shall pay to the Seller total amount within ______ days after the receipt of the goods (This clause is not applied to the Terms of FOB, CFR, CIF).
14. 单据（Documents Required）：
卖方应将下列单据提交银行议付/托收：
The Seller shall present the following documents required to the bank for negotiation/collection:
(1) 标明通知收货人/受货代理人的全套清洁的、已装船的、空白抬头、空白背书并注明运费已付/到付的海运/联运/陆运提单。
Full set of clean on board Ocean/Combined Transportation/Land Bills of Lading and blank endorsed marked freight prepaid/ to collect;
(2) 标有合同编号、信用证号（信用证支付条件下）及装运唛头的商业发票一式＿＿份；
Signed commercial invoice in ______copies indicating Contract No., L/C No. (Terms of L/C) and shipping marks;
(3) 由＿＿＿＿＿＿出具的装箱或重量单一式＿＿份；
Packing list/weight memo in ______ copies issued by＿＿；
(4) 由＿＿＿＿＿＿出具的质量证明书一式＿＿份；
Certificate of Quality in _______ copies issued by＿＿＿＿；
(5) 由＿＿＿＿＿＿出具的数量证明书一式＿＿份；
Certificate of Quantity in ___ copies issued by＿＿＿＿；
(6) 保险单正本一式＿＿份(CIF 交货条件)；
Insurance policy/certificate in ___ copies (Terms of CIF)；
(7)＿＿＿＿签发的产地证一式＿＿份；
Certificate of Origin in ___ copies issued by＿＿＿＿；
(8) 装运通知(Shipping advice): 卖方应在交运后_____小时内以特快专递方式邮寄给买方上述第＿＿项单据副本一式一套。
The Seller shall, within ____ hours after shipment effected, send by courier each copy of the above-mentioned documents No. ＿＿.
15. 装运条款（Terms of Shipment）：
(1) FOB交货方式
卖方应在合同规定的装运日期前30天，以＿＿＿＿方式通知买方合同号、品名、数量、金额、包装件、毛重、尺码及装运港可装日期，以便买方安排租船/订舱。装运船只按期到达装运港后，如卖方不能按时装船，发生的空船费或滞期费由卖方负担。在货物越过船弦并脱离吊钩以前一切费用和风险由卖方负担。
The Seller shall, 30 days before the shipment date specified in the Contract, advise the Buyer by _______ of the Contract No., commodity, quantity, amount, packages, gross weight, measurement, and the date of shipment in order that the Buyer can charter a vessel/book shipping space. In the event of the Seller's failure to effect loading when the vessel arrives duly at the loading port, all expenses including dead freight and/or demurrage charges thus incurred shall be for the Seller's account.
(2) CIF或CFR交货方式
卖方须按时在装运期限内将货物由装运港装船至目的港。在CFR术语下，卖方应在装船前2天以＿＿＿＿方式通知买方合同号、品名、发票价值及开船日期，以便买方安排保险。
The Seller shall ship the goods duly within the shipping duration from the port of loading to the port of destination. Under CFR terms, the Seller shall advise the Buyer by _________ of the Contract No., commodity, invoice value and the date of dispatch two days before the shipment for the Buyer to arrange insurance in time.
16. 装运通知（Shipping Advice）：
一俟装载完毕，卖方应在＿＿小时内以＿＿＿＿方式通知买方合同编号、品名、已发运数量、发票总金额、毛重、船名/车/机号及启程日期等。
The Seller shall, immediately upon the completion of the loading of the goods, advise the Buyer of the Contract No., names of commodity, loading quantity, invoice values, gross weight, name of vessel and shipment date by _________ within ________hours.
17. 质量保证（Quality Guarantee）：
货物品质规格必须符合本合同及质量保证书之规定，品质保证期为货到目的港＿＿个月内。在保证期限内，因制造厂商在
设计
领导形象设计圆作业设计ao工艺污水处理厂设计附属工程施工组织设计清扫机器人结构设计
制造过程中的缺陷造成的货物损害应由卖方负责赔偿。
The Seller shall guarantee that the commodity must be in conformity with the quatity, specifications and quantity specified in this Contract and Letter of Quality Guarantee. The guarantee period shall be ______ months after the arrival of the goods at the port of destination, and during the period the Seller shall be responsible for the damage due to the defects in designing and manufacturing of the manufacturer.
18. 检验（Inspection） （以下两项任选一项）：
（1）卖方须在装运前＿＿日委托＿＿＿＿＿＿检验机构对本合同之货物进行检验并出具检验证书，货到目的港后，由买方委托＿＿＿＿＿＿＿＿检验机构进行检验。
The Seller shall have the goods inspected by ______ days before the shipment and have the Inspection Certificate issued by____. The Buyer may have the goods reinspected by ________ after the goods?rrival at the destination.
(2) 发货前，制造厂应对货物的质量、规格、性能和数量/重量作精密全面的检验，出具检验证明书，并说明检验的技术数据和结论。货到目的港后，买方将申请中国商品检验局(以下简称商检局)对货物的规格和数量/重量进行检验，如发现货物残损或规格、数量与合同规定不符，除保险公司或轮船公司的责任外，买方得在货物到达目的港后＿＿日内凭商检局出具的检验证书向卖方索赔或拒收该货。在保证期内，如货物由于设计或制造上的缺陷而发生损坏或品质和性能与合同规定不符时，买方将委托中国商检局进行检验。
The manufacturers shall, before delivery, make a precise and comprehensive inspection of the goods with regard to its quality, specifications, performance and quantity/weight, and issue inspection certificates certifying the technical data and conclusion of the inspection. After arrival of the goods at the port of destination, the Buyer shall apply to China Commodity Inspection Bureau (hereinafter referred to as CCIB) for a further inspection as to the specifications and quantity/weight of the goods. If damages of the goods are found, or the specifications and/or quantity are not in conformity with the stipulations in this Contract, except when the responsibilities lies with Insurance Company or Shipping Company, the Buyer shall, within _____ days after arrival of the goods at the port of destination, claim against the Seller, or reject the goods according to the inspection certificate issued by CCIB. In case of damage of the goods incurred due to the design or manufacture defects and/or in case the quality and performance are not in conformity with the Contract, the Buyer shall, during the guarantee period, request CCIB to make a survey.
19. 索赔（Claim）：
买方凭其委托的检验机构出具的检验证明书向卖方提出索赔（包括换货），由此引起的全部费用应由卖方负担。若卖方收到上述索赔后______天未予答复，则认为卖方已接受买方索赔。
The buyer shall make a claim against the Seller (including replacement of the goods) by the further inspection certificate and all the expenses incurred therefrom shall be borne by the Seller. The claims mentioned above shall be regarded as being accepted if the Seller fail to reply within ______days after the Seller received the Buyer's claim.
20. 迟交货与罚款（Late delivery and Penalty）:
除合同第21条不可抗力原因外，如卖方不能按合同规定的时间交货，买方应同意在卖方支付罚款的条件下延期交货。罚款可由议付银行在议付货款时扣除，罚款率按每＿＿天收＿＿%，不足＿＿天时以＿＿天计算。但罚款不得超过迟交货物总价的____%。如卖方延期交货超过合同规定＿＿天时，买方有权撤销合同，此时，卖方仍应不迟延地按上述规定向买方支付罚款。
买方有权对因此遭受的其它损失向卖方提出索赔。
Should the Seller fail to make delivery on time as stipulated in the Contract, with the exception of Force Majeure causes specified in Clause 21 of this Contract, the Buyer shall agree to postpone the delivery on the condition that the Seller agree to pay a penalty which shall be deducted by the paying bank from the payment under negotiation. The rate of penalty is charged at______% for every ______ days, odd days less than _____days should be counted as ______ days. But the penalty, however, shall not exceed_______% of the total value of the goods involved in the delayed delivery. In case the Seller fail to make delivery ______ days later than the time of shipment stipulated in the Contract, the Buyer shall have the right to cancel the Contract and the Seller, in spite of the cancellation, shall nevertheless pay the aforesaid penalty to the Buyer without delay.
The buyer shall have the right to lodge a claim against the Seller for the losses sustained if any.
21. 不可抗力（Force Majeure）：
凡在制造或装船运输过程中，因不可抗力致使卖方不能或推迟交货时，卖方不负责任。在发生上述情况时，卖方应立即通知买方，并在＿＿天内，给买方特快专递一份由当地民间商会签发的事故证明书。在此情况下，卖方仍有责任采取一切必要措施加快交货。如事故延续＿＿天以上，买方有权撤销合同。
The Seller shall not be responsible for the delay of shipment or non-delivery of the goods due to Force Majeure, which might occur during the process of manufacturing or in the course of loading or transit. The Seller shall advise the Buyer immediately of the occurrence mentioned above and within_____ days thereafter the Seller shall send a notice by courier to the Buyer for their acceptance of a certificate of the accident issued by the local chamber of commerce under whose jurisdiction the accident occurs as evidence thereof. Under such circumstances the Seller, however, are still under the obligation to take all necessary measures to hasten the delivery of the goods. In case the accident lasts for more than _____ days the Buyer shall have the right to cancel the Contract.
22. 争议的解决 (Arbitration):
凡因本合同引起的或与本合同有关的任何争议应协商解决。若协商不成，应提交中国国际经济贸易仲裁委员会深圳分会，按照申请仲裁时该会现行有效的仲裁规则进行仲裁。仲裁裁决是终局的，对双方均有约束力。
Any dispute arising from or in connection with the Contract shall be settled through friendly negotiation. In case no settlement is reached, the dispute shall be submitted to China International Economic and Trade Arbitration Commission (CIETAC),Shenzhen Commission for arbitration in accordance with its rules in effect at the time of applying for arbitration. The arbitral award is final and binding upon both parties.
23. 通知（Notices):
所有通知用＿＿＿＿文写成，并按照如下地址用传真/电子邮件/快件送达给各方。如果地址有变更，一方应在变更后＿＿日内书面通知另一方。
All notice shall be written in _____ and served to both parties by fax/courier according to the following addresses. If any changes of the addresses occur, one party shall inform the other party of the change of address within ____days after the change.
24. 本合同使用的FOB、CFR、CIF术语系根据国际商会《2000年国际贸易 术语解释通则》。
The terms FOB、CFR、CIF in the Contract are based on INCOTERMS 2000 of the International Chamber of Commerce.
25. 附加条款 (Additional clause)：
本合同上述条款与本附加条款抵触时，以本附加条款为准。
Conflicts between Contract clause hereabove and this additional clause, if any, it is subject to this additional clause.
26. 本合同用中英文两种文字写成，两种文字具有同等效力。本合同共＿＿ 份，自双方代表签字（盖章）之日起生效。
This Contract is executed in two counterparts each in Chinese and English, each of which shall deemed equally authentic. This Contract is in ______ copies, effective since being signed/sealed by both parties.
买方代表（签字）：
Representative of the Buyer
(Authorized signature):
卖方代表（签字）：
Representative of the Seller
(Authorized signature):
一.hereby
英文释义:by means of , by reason of this
中文译词:特此,因此,兹
用法:常用于法律文件、合同、
协议
离婚协议模板下载合伙人协议 下载渠道分销协议免费下载敬业协议下载授课协议下载
书等正式文件的开头语；在条款中需要强调时也可用。
语法：一般置于主语后,紧邻主语.
例1：
The Employer hereby covenants to pay the Contractor in consideration of the execution and completion of the Works and the remedying of defects therein the Contract Price or such other sum as may become payable under the provisions of the Contract at the time and in the manner prescribed by the Contract.
参考译文:
业主特此立约保证在合同规定的期限内,按合同规定的方式向承包人支付合同价,或合同规定的其它应支付的款项,以作为本工程施工、竣工及修补工程中缺陷的报酬。
注释:
(1)hereby: by reason of this 特此
(2)covenant: v. make a formal agreement 立约,签订合同、条约; n. legal agreement具有法律约束的正式合同
(3)completion of the Works: 工程的竣工
(4)therein: in the Works在本工程中
(5)the Contract Price: 合同总价,指工程的总造价
(6)such...as: 关系代词,相当于that, which
(7)under: in accordance with 根据,按照
(8)the provisions of the Contract: terms and conditions of the Contract合同条款
例2：
We hereby certify to the best of our knowledge that the foregoing statement is true and correct and all available information and data have been supplied herein, and that we agree to provide documentary proof upon your request.
注释：
（1）hereby：特此
（2）to the best of our knowledge：as far as we know据我们所知
（3）foregoing statement：above-mentioned statement上述声明
（4）herein：in this, in the statement在声明中
（5）documentary proof：证明文件
参考译文：
特此证明，据我们所知，上述声明内容真实，正确无误，并提供了全部现有的资料和数据，我们同意，应贵方要求出具证明文件。
例3：
This Contract is hereby made and concluded by and between Co. (hereinafter referred to as Party A) and Co. (hereinafter referred to as Party B) on (Date), in (Place), China, on the principle of equality and mutual benefit and through amicable consultation.
注释：
（1）hereby：特此
（2）hereinafter referred to as Party A：以下称甲方
（3）on the principle of equality and mutual benefit：在平等互利基础上
（4）through amicable consultation：通过友好协商
参考译文：
本合同双方， 公司（以下称甲方）与 公司（以下称乙方），在平等互利基础上，通过友好协商，于 年 月 日在中国 （地点），特签订本合同。
例4：
This agreement is hereby made and entered into on (Date), by and between Co. China (hereinafter referred to as Party A) and Co. (hereinafter referred to as Party B).
注释：
（1）this agreement is hereby made and entered into：特此订立本协议
在法律文件中表示“订立本协议”可用以下4个动词：sign (make, conclude or enter into) this agreement, 按照同义词连用的写作特点，可用上述4个动词中的两个来表示）。
（2）hereinafter referred to as Party B：以下简称乙方
参考译文：
本协议特由中国 公司（以下简称甲方）与 公司（以下简称乙方）于 年 月 日订立。
二 hereof
英文释义: of this
中文译词:关于此点；在本文件中
用法:在表示上文已提及的“本合同的、本文件的……”时，使用该词。例如表示本合同条件、条款时，可以说“the terms, conditions and provisions hereof”，这里hereof表示“of this Contract”；又如表示本工程的任何部分，可用“any parts hereof”，这里hereof表示“of this Works”。
语法：一般置于要修饰的名词的后面，与之紧邻。
hereof和thereof的区别：hereof强调“of this”。例如，上面的“the terms, conditions and provisions thereof”中的thereof表示of the Contract；“any parts thereof”中的thereof表示of the Works。
例1
Whether the custom of the Port is contrary to this Clause or not, the owner of the goods shall, without interruption, by day and night, including Sundays and holidays (if required by the carrier), supply and take delivery of the goods. Provided that the owner of the goods shall be liable for all losses or damages including demurrage incurred in default on the provisions hereof.
注释：
（1） Whether the custom of the Port is contrary to this Clause or not：不论港口习惯是否与本款规定相反，whether… or not：不论……是否
（2） the owner of the goods：货方
（3） without interruption：无间断地
（4） carrier：承运人
（5） in default on the provisions hereof：违反本款规定 hereof：of this Clause
参考译文：
不论港口习惯是否与本款规定相反，货方都应昼夜地，包括星期日和假日（如承运人需要），无间断地提供和提取货物。货方对违反本款规定所引起的所有损失或损坏，包括滞期应负担赔偿责任。
例2
Foreign trade dealers as mentioned in this Law shall, in accordance with the provisions hereof, cover such legal entities and other organization as are engaged in foreign trade dealings.
注释：
（1） foreign trade dealers：对外贸易经营者
（2） as mentioned in this Law：本法所称
（3） the provisions hereof：the provisions of this Law 本法规定
（4） legal entity：法人
（5） be engaged in foreign trade dealings：从事对外贸易经营活动
参考译文：
本法所称对外贸易经营者，是指依照本法规定从事对外贸易经营活动的法人和其他组织。
例3
The establishment of a limited liability company or a company limited by shares shall comply with the conditions and provisions of this Law. A company complying with the conditions and provisions hereof may be registered as a limited liability company or a company limited by shares. Provided that if a company fails to comply with the conditions and provisions hereof, the company in question shall not be registered as a limited liability company or a company limited by shares.
注释：
（1）a limited liability company：有限责任公司
（2）a company limited by shares：股份有限公司
（3）provisions hereof：本法规定 hereof: of this Law
（4）may be registered as：登记为
参考译文：
设立有限责任公司、股份有限公司，必须符合本法规定的条件。符合本法规定的条件的，登记为有限责任公司或者股份有限公司；不符合本法规定的条件的，不得登记为有限责任公司或股份有限公司。
例4
If, as a result of withdrawal or any other reasons, an arbitrator fails to perform his duties as an arbitrator, another arbitrator shall, in accordance with the provisions hereof, be selected or appointed.
注释：
（1） as a result of withdrawal or any other reasons：回避或者其它原因
（2） arbitrator：仲裁员
（3） the provisions hereof：the provisions of this Law 本法规定
（4） be selected or appointed：选定或指定
参考译文：
仲裁员因回避或者其它原因不能履行职责的，应当依照本法规定重新选定或指定仲裁员。
例5
In the event of conflict between the provisions on arbitration formulated and prepared prior to the effective date of this Law and the provisions of this Law, the provisions hereof shall prevail.
注释：
（1） conflict：相抵触
（2） prior to the effective date of this Law：本法施行前
（3） the provisions hereof shall prevail：以本法为准 hereof：of this Law
参考译文：
本法施行前制定的有关仲裁的规定与本法的规定相抵触的，以本法为准。
例6
Where, in accordance with laws, the circumstance(s) specified in Article 15 and Article 16 of this Law is /are confirmed, the organization with compensatory obligations shall pay compensation in any of the circumstance in question.
Where the claimant for compensation demands the confirmation of one of the circumstances specified in Article 15 and Article 16 hereof, and the demanded organization refuses to make the confirmation, the claimant shall have the right to lodge a complaint. Where the claimant claims compensation, the claim, shall, first, be lodged to the organization for compensatory obligations.
The provisions of Article 10, Article 11 and Article 12 hereof shall apply to/ in the procedures of compensation.
注释：
（1） the organization with compensatory obligations：赔偿义务机关
（2） shall pay compensation：应当给予赔偿
（3） the claimant for compensation：赔偿请求人
（4） Article 15 and Article 16 hereof：本法第十五条、第十六条 hereof：of this Law
（5） shall have the right to lodge a complaint：有权申诉
（6） claims compensation：要求赔偿
（7） apply to/ in：适用 More Examples: The comment applies equally here. /That argument does not apply in this case. /That applies to at least nine-tenths of the people we see about. /These remarks apply to every town in this kingdom. /The rules of safe driving apply to everyone.
参考译文：
赔偿义务机关对依法确认有本法第十五条、第十六条规定的情形之一的，应当给予赔偿。
赔偿请求人要求确认有本法第十五条、第十六条规定情形之一的，被要求的机关不予确认的，赔偿请求人有权申诉。赔偿请求人要求赔偿，应当先向赔偿义务机关提出。赔偿程序适用本法第十条、第十一条、第十二条的规定。
例7
If an arbitrator involved in one of circumstances specified in Item 4, Article 34 of this Law, and if it is serious, or those specified in Item 6, Article 58 hereof, the arbitrator in question shall, in accordance with the law, bear the legal liability and responsibility. The arbitration commission shall remov
浙公网安备 33021202002483